Termination For Default: The “No Reasonable Likelihood” Standard

Sometimes you may find yourself running late. It happens to the best of us for a multitude of reasons. But what happens to federal contractors when they are running late in performing under a contract and there is “no reasonable likelihood” of timely performance?

Unfortunately for contractors in this position, as illustrated by a recent Civilian Board of Contract Appeals (CBCA) decision, the result may be a default termination.

Continue reading

Excusable Delay: Government’s Failure To Extend Was “Constructive Acceleration”

Federal contractors not so infrequently find themselves in a position where they are unable to complete performance of a contract by the agreed-upon deadline. So, what happens when the delay is neither party’s fault, but the government denies extension of the period of performance or provides inadequate extensions?

In IAP Worldwide Services, Inc. (ASBCA Nos. 59397, 59398, and 59399), the Armed Services Board of Contract Appeals found under the legal theory of “constructive acceleration” that the U.S. Army Corps of Engineers was liable for extra costs incurred by IAP due to the Corps insistence of timely contract delivery despite excusable delays.

Continue reading